THESE VENDOR TERMS AND CONDITIONS (THESE “TERMS”) TOGETHER WITH: (I) ANY PURCHASE ORDER(S) ISSUED BY FITBIT; AND/OR (II) ANY ORDER FORM(S), STATEMENT(S) OF WORK, OR SIMILAR DOCUMENTS EXECUTED BY BOTH PARTIES THAT INDICATE THAT THEY ARE GOVERNED BY OR SUBJECT TO THESE TERMS (EACH, AN “ORDERING DOCUMENT” AND COLLECTIVELY WITH THESE TERMS AND ANY ADDITIONAL TERMS LINKED BELOW OR OTHERWISE REFERENCED HEREIN, COLLECTIVELY, THE “AGREEMENT”) SET FORTH THE TERMS AND CONDITIONS THAT APPLY TO ANY PURCHASE OF GOODS, RECEIPT OF SERVICES OR DELIVERABLES AND/OR USE OF SOFTWARE BY FITBIT AS PROVIDED BY VENDOR PURSUANT TO THE APPLICABLE ORDERING DOCUMENT(S).
As used herein, the term “Fitbit” shall mean the Fitbit legal entity indicated on the applicable Ordering Document(s) and the term “Vendor” shall mean Vendor’s legal entity providing the Goods, Services, Software or Deliverables identified on the Ordering Documents and such Vendor’s Affiliates. “Affiliate” shall mean with respect to a party hereto, any legal entity, whether existing now or in the future, that either directly or indirectly controls, is controlled by or is under common control with such party. Any capitalised terms used but not defined in these Terms will have the meanings set forth in the Additional Terms linked below.
The following additional terms and conditions (“Additional Terms”) will apply to Vendor’s provision of Goods, Services, or Software purchased under an Ordering Document:
In the event of a conflict among these Terms, any Additional Terms or an Ordering Document, the terms of the applicable Ordering Document will control over any conflict with these Terms or the Additional Terms.
The following additional terms and conditions apply to all Ordering Documents.
The Agreement is effective as the date of the applicable Ordering Document and shall continue in force and effect as set forth in the Ordering Document.
“Confidential Information” means information disclosed by one party to the other that is marked as confidential or proprietary or that ought reasonably to be understood as confidential or proprietary, including, without limitation, any research, products, services, developments, inventions, discoveries, ideas, concepts, software, designs, drawings, engineering, specifications, documentation, processes, techniques, models, source code, object code, diagrams, flow charts, procedures, business and marketing plans or strategies, business opportunities, financial information, pricing information, sales information, customer and supplier information, and the terms of the Ordering Documents. Confidential Information excludes information that the recipient already lawfully knew, that becomes public through no fault of the recipient, that was independently developed by the recipient or that was rightfully obtained by recipient from a third party.
The recipient agrees not to disclose Confidential Information except to its Affiliates, and its and their employees, consultants, and agents who need to know it and have agreed in writing to keep it confidential. Only those parties may use the Confidential Information, and only to exercise the recipient’s rights and fulfil its obligations under the Agreement and shall at all times use at least a reasonable degree of care to protect it. The recipient may also disclose Confidential Information to the extent required by law or by the rules or requirements of any stock exchange on which the securities of the recipient is listed, but in any event only after reasonable notice to the disclosing party and cooperating in an attempt to obtain confidential treatment. Unauthorised disclosure of Confidential Information shall cause harm not compensable by damages, and the disclosing party shall be entitled to seek injunctive or equitable relief in a court of competent jurisdiction, without posting a bond, to protect its Confidential Information.
Vendor may from time to time provide suggestions, comments or other feedback (“Feedback”) to Fitbit with respect to the Confidential Information provided by Fitbit. Vendor agrees that all Feedback is and shall be given voluntarily. Feedback, even if designated as confidential by Vendor, shall not, absent a separate written agreement, create any confidentiality obligation for, or upon, Fitbit. Furthermore, except as otherwise provided herein or in a separate subsequent written agreement between the parties, Fitbit shall be free to use, disclose, reproduce, license or otherwise distribute and exploit any Feedback as it sees fit (entirely without obligation or restriction of any kind on account of intellectual property rights or otherwise) or to pay any royalties or other compensation in connection therewith.
For any Goods that Vendor properly delivers, any Services that Vendor properly performs or any Software properly provided (in connection with the foregoing “properly” shall mean in accordance with any and all terms and conditions set forth in the Agreement), Fitbit will be responsible to pay Vendor the amount(s) specified as and when specified on the applicable Ordering Document(s). For clarity, with respect to any Goods, Services or Software that are subject to acceptance by Fitbit, as indicated in the applicable Ordering Documents, Fitbit will have no obligation to pay any related fees unless and until it has accepted the applicable Goods, Services or Software pursuant to the applicable acceptance terms. Fitbit will also reimburse the reasonable, pre-approved travel and related expenses incurred by Vendor in providing any Goods, Services, or Software if specified in the applicable Ordering Document, but only in accordance with Fitbit’s then-current travel and expense policies. If no expenses are specified in the applicable Ordering Documents, then Fitbit shall have no liability for any requested reimbursement of expenses. For any amounts that properly become due in accordance herewith, Vendor shall invoice Fitbit in a timely manner, but in any event no later than sixty (60) days from proper delivery of Goods, performance of Services, or provision of Software, as applicable. If Vendor fails to do so, Fitbit shall have no obligation to pay any such amounts.
Fitbit will pay the undisputed portion of Vendor’s invoices therefore in accordance with the timing specified on the Ordering Document, or if no timing is specified on the Ordering Document then within sixty (60) days after Fitbit’s receipt of the undisputed invoice. Vendor shall ensure that each invoice contains a reasonable level of detail as is necessary for Fitbit to determine that such invoice has been billed in accordance with the terms and conditions of the Agreement, including, without limitation, to the extent applicable: (i) reference to the applicable Fitbit purchase order number; (ii) each applicable tax; and (iii) any other information specified in any Ordering Documents or otherwise requested by Fitbit from time to time. All payments due to Vendor pursuant to an Ordering Document are subject to offset, which may be applied by Fitbit in its sole and absolute discretion from time to time and at any time for any amounts owed by Vendor to Fitbit and/or its Affiliates.
If Fitbit disputes any amount contained on an invoice (each, a “Billing Dispute”), Fitbit will notify Vendor in writing of the nature of the Billing Dispute as promptly as practicable after its determination that such a dispute exists. Fitbit may withhold payment of the disputed amounts and such payment will not be considered past due while the parties work in good faith to resolve the Billing Dispute. The parties will work in good faith to resolve each Billing Dispute within thirty (30) days following the date on which Vendor received Fitbit's notification thereof. If the parties are unable to resolve the Billing Dispute within such thirty (30) day period, it may be resolved pursuant to the dispute resolution section of the Agreement.
Unless otherwise specified in an Ordering Document, the prices set forth in the Ordering Document include, without limitation, all applicable federal, state and local taxes and Fitbit shall not have any liability to reimburse Vendor or otherwise pay for any such taxes.
In addition to any specific insurance coverage requirements set forth in any Ordering Document, Vendor shall at all times during the term maintain any insurance coverage that is required by law and/or as is the common practice in Vendor's business, which may include, without limitation, health, workers' compensation, unemployment compensation, disability, liability, or car insurance. Upon request, Vendor shall promptly provide Fitbit with certificates of insurance or evidence of coverage reflecting that it is in compliance with the foregoing and naming Fitbit as an additional insured with respect to such coverage. Notwithstanding the generality of the foregoing, Vendor shall always maintain adequate insurance coverage for any Fitbit property under the care, custody or control of Vendor during its performance of its obligations under the Agreement.
In addition to any termination rights set forth in any Ordering Document and/or the Additional Terms, Fitbit may immediately terminate the Agreement and/or any Ordering Document upon written notice to Vendor if: (i) Vendor is in breach of the Agreement and, if curable, fails to cure such breach with ten (10) days of notice thereof; or (ii) Vendor files a petition in bankruptcy, becomes insolvent, or dissolves. Unless otherwise specified in an Ordering Document, Fitbit shall only be liable for any Goods or Software properly provided or Services properly performed through the date of termination.
Termination of the Agreement is not an exclusive remedy and the exercise of either party of any remedy under the Agreement will be without prejudice to any other remedies it may have under the Agreement, by law or otherwise.
Vendor represents and warrants that: (i) its performance under the Agreement will not conflict with, or be prohibited in any way by, any other agreement or statutory restriction to which it is bound; (ii) it has the full right and power to enter into and perform the Agreement without the consent of any third party; and (iii) there are no pending claims, suits, actions, allegations, charges, or investigations brought by a third party, governmental authority or industry body (“Third Party Actions”), and Vendor is not aware of any threatened Third Party Actions, that would prevent Vendor from performing under the Agreement. Vendor will promptly notify Fitbit if it becomes aware of any circumstances that arise that may or would cause Vendor to be in violation of the representations and warranties set forth herein.
EXCEPT FOR VENDOR’S WARRANTIES SET FORTH IN THIS AGREEMENT, EACH PARTY EXPRESSLY DISCLAIMS ANY AND ALL OTHER WARRANTIES OF ANY KIND OR NATURE, WHETHER EXPRESS OR IMPLIED, INCLUDING, WITHOUT LIMITATION, THE IMPLIED WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE.
Vendor will defend, indemnify and hold harmless Fitbit, its Affiliates and its and their officers, directors, employees and agents, from and against any and all Third Party Actions and all related losses, liabilities, damages, expenses and costs arising from or relating to: (i) any breach or alleged breach of any representation, warranty or other term or condition of this Agreement by Vendor; (ii) any infringement or alleged infringement by Vendor and/or any Goods, Services (including, without limitation, any Deliverable resulting therefrom) or Software provided by Vendor of any third-party’s intellectual property rights; or (iii) any injury including bodily injury, disability or death, personal injury or property damage in any way attributable to, or arising out of, the performance by Vendor under the Agreement, including, without limitation, claims arising out of any negligent or intentional act or omission of Vendor, its employees, contractors or permitted subcontractors.
Fitbit will give Vendor prompt written notice of any Third Party Action for which it is seeking indemnity pursuant hereto. Vendor shall control the defence and settlement of such Third Party Action, but Fitbit shall have the right to participate in the defence of any such Third Party Action with counsel of its own choosing at Fitbit’s cost. In no event will Vendor settle, compromise or consent to the entry of a judgment in a manner that would impose any unindemnified or non-monetary liability on Fitbit without Fitbit’s prior written consent, which shall not be unreasonably withheld.
If Fitbit’s, any of its Affiliates’, or its or their assigns’ use of any Goods, Services (including, without limitation, any Deliverable resulting therefrom), or Software provided by Vendor are enjoined or are threatened by injunction, then Vendor shall, at its cost use reasonable efforts to obtain for Fitbit, its Affiliates and its and their assigns, the right to continue using the applicable Goods, Services, Deliverables, or Software. If Vendor is unable to do so in a manner and time period that is acceptable to Fitbit (in its reasonable determination), then Vendor shall at its cost and at Fitbit’s option either: (a) substitute fully equivalent non-infringing Goods, Services, Deliverables, or Software, as applicable, or (b) refund in full the price paid by Fitbit for the applicable Goods, Services, Deliverables, or Software.
EXCEPT WITH RESPECT TO VENDOR’S VIOLATION OF ITS CONFIDENTIALITY OBLIGATIONS UNDER THE AGREEMENT, VENDOR’S INDEMNITY OBLIGATIONS UNDER THE AGREEMENT, OR ANY CLAIM ARISING AS A RESULT OF VENDOR’S BREACH OF ANY OF THE ADDITIONAL TERMS APPLICABLE TO FITBIT DATA, FITBIT SYSTEMS AND/OR FITBIT FACILITIES: (I) NEITHER PARTY SHALL BE LIABLE FOR ANY LOSS OF USE, INTERRUPTION OF BUSINESS, LOST PROFITS, OR ANY INDIRECT, SPECIAL, INCIDENTAL, OR CONSEQUENTIAL DAMAGES OF ANY KIND REGARDLESS OF THE FORM OF ACTION WHETHER IN CONTRACT, TORT (INCLUDING NEGLIGENCE), STRICT PRODUCT LIABILITY, OR OTHERWISE, EVEN IF IT HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES; AND (II) IN NO EVENT SHALL EITHER PARTY’S AGGREGATE LIABILITY UNDER THE AGREEMENT EXCEED THE AMOUNTS PAID OR DUE TO BE PAID TO VENDOR PURSUANT TO THE AGREEMENT.
Both parties shall comply with, and Vendor shall ensure that its permitted subcontractors comply with, all applicable laws and regulations in their performance under the Agreement (including, without limitation, the applicable laws, orders, policies and regulations of the jurisdiction in which Goods, Services, Deliverables, or Software are provided, including, without limitation, those relating to import, export and re-export of commodities, technical data and software, privacy, labour and employment, anti-discrimination and anti-harassment, freedom of association, environmental protection, hazardous substances management, pollution prevention and resource sustainability, waste management, recycling, protection of intellectual property, and anti-bribery and anti-corruption).
Notwithstanding the generality of the foregoing, both parties shall comply with, and Vendor shall ensure that its permitted subcontractors comply with, all applicable laws and regulations enacted to combat bribery and corruption, including, without limitation, the United States Foreign Corrupt Practices Act, the UK Bribery Act, the principles of the OECD Convention on Combating Bribery of Foreign Public Officials, and any corresponding laws of all countries where any Goods, Services, Deliverables, or Software are provided.
Furthermore, Vendor agrees that it will not export, re-export, resell or transfer any Fitbit information or technology: (i) in violation of any limitations imposed by the United States or any other jurisdiction, or (ii) to any country for which an export license or other governmental approval is required at the time of export, without first obtaining all necessary licenses or other approvals.
In support thereof, from time to time, upon Fitbit’s request, Vendor shall promptly complete a certificate representing and warranting to Fitbit its ongoing compliance with any and all laws and regulations applicable to its performance under the Agreement, as well as to furnish to Fitbit any information Fitbit reasonably determines is necessary for it to ascertain that Vendor is performing in compliance therewith.
Vendor and any permitted subcontractors shall abide by the requirements of 41 CFR §§ 60-1.4(a), 60-300.5(a) and 60-741.5(a). These regulations prohibit discrimination against qualified individuals based on their status as protected veterans or individuals with disabilities, and prohibit discrimination against all individuals based on their race, color, religion, gender identity, sexual orientation, sex, or national origin. Moreover, these regulations require that Vendor and any permitted subcontractor take affirmative action to employ and advance in employment individuals without regard to race, colour, religion, sex, national origin, protected veteran status or disability.
Except as specifically approved by Fitbit in advance in writing (email is sufficient) Vendor will not use Fitbit's trademarks, service marks, trade names, logo or other product or service designations for any purpose, or make any public statement whatsoever (including, without limitation, press releases) regarding the existence of or details regarding the parties' relationship. In the event that Fitbit provides such written approval, all use of Fitbit’s trademarks, service marks, trade names, logo or other product or service designations shall be subject to the then-current trademark policy available at https://www.fitbit.com/legal, and any other guidelines or policies as Fitbit may provide from time to time.
No right or obligation under the Agreement may be assigned by Vendor without the prior written consent of Fitbit, and any purported assignment without such consent will be null and void ab initio. Fitbit may, at any time and from time to time, assign any or all of its rights and obligations under the Agreement to any of its Affiliates. The Agreement shall be binding upon and inure to the benefit of the parties hereto and their respective successors and permitted assigns, if any.
Unless otherwise specified in an Ordering Document, Vendor may not subcontract its performance hereunder without the prior express approval by Fitbit in advance in writing (email is sufficient). To the extent any subcontracting is specified in an Ordering Document or otherwise authorized by Fitbit in writing in advance, Vendor will: (i) remain directly responsible to Fitbit for the acts or omissions of each subcontractor; and (ii) ensure that each subcontractor is bound in writing to terms at least as protective of Fitbit as the terms and conditions of the Agreement.
Unless otherwise specified in an Ordering Document, Vendor will keep and maintain complete and accurate records relevant to its performance under the Agreement and will retain those records for as long as is required by law and/or as is the common practice in Vendor's business.
Fitbit or its nominee may, upon reasonable notice to Vendor, audit those relevant records of Vendor to ensure its compliance with the terms and conditions of the Agreement. Any such audit shall be conducted in a manner as to not unreasonably interfere with Vendor’s business activities. If any such audit reveals that Vendor has breached any material term of the Agreement (as determined by Fitbit in its reasonable determination), then Vendor shall pay Fitbit’s costs and expenses of conducting such audit and promptly remedy the breach.
All notices required or permitted by the Agreement must be in writing addressed to an authorized representative of the other party. In the case of a notice to Vendor, such notice will be deemed given when sent by confirmed email to an authorized representative of Vendor as specified in the applicable Ordering Document. In the case of a notice to Fitbit, such notice will be deemed given when sent by confirmed email to an authorized representative of Fitbit with a copy to email@example.com.
Vendor is an independent contractor and no partnership or joint venture shall be deemed to exist between them as a result of the relationship contemplated hereby. The Agreement does not constitute authority for Vendor to act for Fitbit as its agent or make commitments for Fitbit. Vendor shall be responsible for all costs and expenses incident to providing the Goods, Services, Deliverables or Software.
If any provision of the Agreement is held invalid or unenforceable to any extent or in any application, the remainder of the terms of the Agreement, or the application thereof to different persons or circumstances or in different jurisdictions, shall not be affected thereby.
Unless otherwise specified in an Ordering Document, this Agreement shall be governed by the laws of the State of California, without reference to conflict of laws principles. The parties expressly agree that the provisions of the United Nations Convention on Contracts for the International Sale of Goods will not apply to the Agreement or to their relationship.
If there is a dispute between the parties arising out of, or in connection with, the Agreement the parties agree that they will first attempt to resolve the dispute through good faith negotiations between one or more senior management members of each party. If either party believes that such negotiations will not result in a resolution, then it shall so notify the other party and thereafter either party may commence litigation in the state or federal courts in San Francisco County, California. The parties irrevocably submit to the exclusive jurisdiction of those courts and agree that final judgment in any action or proceeding brought in such courts will be conclusive and may be enforced in any other jurisdiction by suit on the judgment (a certified copy of which will be conclusive evidence of the judgment) or in any other manner provided by law. Each party irrevocably waives to the fullest extent permitted by applicable law: (i) any objection it may have to the laying of venue in any court referred to above; (ii) any claim that any such action or proceeding has been brought in an inconvenient forum; and (iii) any immunity that it or its assets may have from any suit, execution, attachment (whether provisional or final, in aid of execution, before judgment or otherwise) or other legal process.
Notwithstanding anything to the contrary in the Agreement, either party may at any time seek equitable relief in order to protect its confidential information or intellectual property; provided that it must do so in the state or federal courts in San Francisco County, California. The parties hereby waive any bond or other security requirements that may be necessary for obtaining equitable relief.
In any action to enforce the terms and conditions of the Agreement, the prevailing party shall be entitled to recover all court costs, reasonable attorneys' fees and related expenses, in addition to any other relief to which it may be entitled.
Any rights and obligations that by their nature extend beyond the expiration or termination of the Agreement shall survive the expiration or termination of the Agreement, including, without limitation, each party’s confidentiality obligations, Vendor’s indemnification obligations and the limitation of liability.
Neither party will be liable for any failure to perform, caused by circumstances beyond its reasonable control and not reasonably foreseeable and preventable, including, without limitation, fire, earthquake, flood, acts of God, acts of war, acts or terrorism, government action, pandemic, epidemic, or other similar catastrophic occurrences (each, a “Force Majeure Event”). The obligations of a party that are prevented from being performed (“Non-performing Party”) by a Force Majeure Event shall be extended on a day-to-day basis for the time period that the Force Majeure Event prevents such performance, so long as the Non-performing Party: (i) promptly notifies the other party of the occurrence of the Force Majeure Event, its effect on performance, and how long it is expected to last; (ii) updates such information as reasonably necessary; and (iii) uses reasonable efforts to limit any loss or damages to the other party, mitigate the delay, and resume performance as soon as practicable. Should a Force Majeure Event continue for more than ten (10) consecutive days, Fitbit may terminate the Agreement and/or any affected Ordering Document upon written notice to Vendor, will have no liability in connection therewith and shall be entitled to a refund of any amounts paid in connection with any Goods that have yet to be delivered, Services that have yet to be performed or remaining period of any Software Subscription Term.
No failure or delay of either party in exercising at any time any of its rights, powers or remedies under the Agreement, in exercising any election or option provided herein, or in requiring the performance by the other party of any of the provisions herein will in any way be construed to be a waiver of such provisions, and any waiver of any provision granted on one occasion shall not be deemed a waiver of such provision on other occasions.
The version of these Terms and any Additional Terms in effect as of the date of the applicable Ordering Document(s) will govern the provision of Goods, Services, or Software pursuant thereto. Fitbit shall at all times have the right to make changes to these Terms and any Additional Terms provided that such changes shall only apply to any Ordering Document subsequently entered into by the parties.